ОБ ЭТОМ ЭПИЗОДЕ
What happens when an employer's own conduct prevents the contractor from meeting the contractual completion date? And what are the consequences when a contract has no effective mechanism to deal with acts of prevention? In the first episode of the Construction Law Shortcast, Xavier Milne and Noe Minamikata tackle two foundational principles of English construction law that anyone involved in construction projects needs to understand: the prevention principle and time at large.
These concepts have significant practical implications for the completion date, liquidated damages regime, and other contractual relief potentially available to the parties. A concise breakdown of two principles that neither employers nor contractors should overlook.
These concepts have significant practical implications for the completion date, liquidated damages regime, and other contractual relief potentially available to the parties. A concise breakdown of two principles that neither employers nor contractors should overlook.
английский
США
РАСШИФРОВКА 🔗
Are you the producer of this podcast?
Add a podcast transcript
Need Audio-to-Text?
Transcribe with Listen411 in Just 60 Seconds
ПОИСК ПРОШЛЫХ ЭПИЗОДОВ
Искать прошлые эпизоды Herbert Smith Freehills Kramer Podcasts.
ДРУГИЕ ЭПИЗОДЫ В ЭТОМ ПОДКАсте
In this episode, partners Jason Betts and Aoife Xuereb speak with Sophie East and Jesse Wilson, partners at Bell Gully, about the evolving class actions landscape in New Zealand and how it compares with developments across the Tasman.
They explore the foundations of New Zealand's representative pr…
This is the fourth episode of "Cross-examining AI", HSF Kramer's podcast series on disputes and AI where we unpack the key developments that are shaping litigation. In this episode we look at the UKJT’s statement on liability for AI harms, the SRA’s recent warning notice on AI and the first case fr…
In this episode we explore a challenge that receives far less attention than AI: how organisations identify and collect data in an increasingly fragmented communications landscape.
From disappearing messages and encrypted devices to AI-generated transcripts and summaries, our speakers, Stephanie B…
Welcome to Cross Examining Cyber, a podcast brought to you by Herbert Smith Freehills Kramer. In this series, we speak with leading cyber practitioners, business leaders and policymakers about the issues shaping today's cyber landscape, from emerging threats and regulatory developments to governanc…
In this episode, partners Jason Betts and Anna Sutherland speak with the Honourable Justice Wigney of the Federal Court of Australia, one of Australia's most experienced judges in complex commercial litigation and representative proceedings, about the growing complexity of modern litigation and its…
Отказ от ответственности: Подкаст и иллюстрации, встроенные в эту страницу, взяты из Herbert Smith Freehills Kramer Podcasts, который является собственностью его владельца и не связан или не одобрен Listen Notes, Inc.
ИЗМЕНИТЬ
Спасибо, что помогаете поддерживать базу подкастов актуальной.
